Service Tax Appeal No.11918 of 2018
(Arising out of OIA-35-AGU-ADT-VAD-2017-18 dated 19/04/2018 passed by Commissioner
( Appeals ) Commissioner of Central Excise, Customs and Service Tax-VADODARA-I)
Krishak Bharti Co Operative Ltd
VERSUS
C.C.E. & S.T.-Surat-i
WITH
Service Tax Appeal No.12872 of 2018
(Arising out of OIA-CCESA-SRT-APPEALS-PS-198-2017-18 dated 31/07/2018 passed by
Commissioner ( Appeals ) Commissioner of Central Excise, Customs and Service Tax
SURAT-I)
Krishak Bharti Co Operative Ltd
VERSUS
C.C.E. & S.T.-Surat-i
APPEARANCE:
Shri Jigar Shah, Advocate for the Appellant
Shri Dinesh Prithiani, Assistant Commissioner (AR) for the Revenue
CORAM: HON’BLE MEMBER (JUDICIAL), MR. RAMESH NAIR
HON’BLE MEMBER (TECHNICAL), MR. RAJU
Final Order No. A/ 10028-10029 /2023
DATE OF HEARING: 29.09.2022
DATE OF DECISION: 10.01.2023
RAJU
These appeals have been filed by M/s. Krishak Bharti Co Operative Ltd
against confirmation of demand of service tax.
- Learned counsel pointed out that the appellants are engaged in the
manufacture of fertilizers.
2.1 He pointed out that the appellant assigned work order to various
companies for construction/erection of civil structures and other allied works.
He pointed out that the work order/contract is the time based contract with
price reduction clause for delay in completion of work. He particularly
highlighted clause 13 of the Work order which reads as follows:-
―13.0 Price reduction clause- Timely completion of entire work shall be
the essence of contract. In the event of delay in completion of work
beyond seven days, as indicated in LOI/Work order, @5% of total order
value shall be recovered. Price reduction shall be applicable as per Article
No.25(g) of General Conditions of Contract.‖
He argued that demand of service tax has been sought to be raised under
clause 66E(e) of the Finance Act, 1994, the said clause reads as follows:-
“66E. Declared services
The following shall constitute declared services, namely:-
………….
(e) agreeing to the obligation to refrain from an act, or to
tolerate an act or a situation, or to do an act,”
2.2 He further pointed out that the demand under the same clause is also
sought to be raised in respect of recoveries made from the employees in
case they violate the terms of employment contract. He pointed out that
when trainees are employed by the appellant, the appellant spent a
significant amount of time and money in training the employees therefore,
the employment contract has various conditions put on the trainees. In case
the trainee breaches any of those conditions, a specific amount is
recoverable from the trainees. The said amount is also sought to be taxed
under Section 66E(e) of the Finance Act, 1994.
2.3 Learned counsel pointed out that this issue has been clarified by CBIC
vide circular no.178/10/2022-GST dated 3rd August, 2022 where various
situations arising on which disputes have arisen under Section 66E(e) of the
Finance Act, 1994 have been clarified.
- Learned AR relies on the impugned order.
- We have considered the rival submissions. We find that the CBIC has
issued a circular No.178/10/2022-GST dated 3rd August, 2022 in which it has
stated its stand on the issue of taxability of various transactions claimed to
be “liquidated damages”. At the time of adjudication by commissioner and
hearing before tribunal, this circular was not available on record and
therefore, the adjudicating authority could not take benefit of the same.
While the issue of levibility of service tax on liquidated damages is a
debatable issue, the CBIC has vide Circular No. 178/10/2022-GST clarified
its stand on the subject in respect of GST. In terms of Para 5(e) of Schedule
II of CGST Act as supply the following is an taxable transaction as deemed
supplies.
SCHEDULE II
ACTIVITIES [OR TRANSACTIONS] TO BE TREATED AS SUPPLY OF GOODS
OR SUPPLY OF SERVICES
- Supply of services
The following shall be treated as supply of services, namely :—
(a) ……..
(b) ……..
(c) …….
(d) ……..
(e) agreeing to the obligation to refrain from an act, or to
tolerate an act or a situation, or to do an act; and
(f) ……
In terms of section 66E(e) of the Finance Act, 1994 the following was a
taxable transaction as a declared service, the same is reproduced below:-
“66E. Declared services
The following shall constitute declared services, namely:-
………….
(e) agreeing to the obligation to refrain from an act, or to
tolerate an act or a situation, or to do an act,”
- In the aforesaid circular dated 03.08.2022, the CBIC has clarified its
stand on plethora of situation which includes the dispute in the instant case
as well. The circular reads as follows:-
―In certain cases/instances, questions have been raised regarding taxability
of an activity or transaction as the supply of service of agreeing to the
obligation to refrain from an act or to tolerate an act or a situation, or to do
an act. Applicability of GST on payments in the nature of liquidated damage,
compensation, penalty, cancellation charges, late payment surcharge etc.
arising out of breach of contract or otherwise and scope of the entry at para
5 (e) of Schedule II of Central Goods and Services Tax Act, 2017
(hereinafter referred to as, “CGST Act”) in this context has been examined
in the following paragraphs.
- “Agreeing to the obligation to refrain from an act or to tolerate an act or a
situation, or to do an act” has been specifically declared to be a supply of
service in para 5 (e) of Schedule I of CGST Act if the same constitutes a
“supply” within the meaning of the Act. The said expression has following
three limbs:
- a. Agreeing to the obligation to refrain from an act
Example of activities that would be covered by this part of the expression
would include non-compete agreements, where one party agrees not to
compete with the other party in a product, service or geographical area
against a consideration paid by the other party.
Another example of such activities would be a builder refraining from
constructing more than a certain number of floors, even though permitted to
do so by the municipal authorities, against a compensation paid by the
neighbouring housing project, which wants to protect its sunlight, or an
industrial unit refraining from manufacturing activity during certain hours
against an agreed compensation paid by a neighbouring school, which wants
to avoid noise during those hours.
- Agreeing to the obligation to tolerate an act or a situation
This would include activities such a shopkeeper allowing a hawker to
operate from the common pavement in front of his shop against a monthly
payment by the hawker, or an RWA tolerating the use of loud speakers for
early morning prayers by a school located in the colony subject to the school
paying an agreed sum to the RWA as compensation.
- Agreeing to the obligation to do an act
This would include the case where an industrial unit agrees to install
equipment for zero emission/discharge at the behest of the R WA of a
neighbouring residential complex against a consideration paid by such RWA,
even though the emission/discharge from the industrial unit was within
permissible limits and there was no legal obligation upon the individual unit
to do so.
- The description “agreeing to the obligation to refrain from an act or to
tolerate an act or a situation, or to do an act” was intended to cover services
such as described above. However, over the years doubts have persisted
regarding various transactions being classified under the said description.
3.1. Some of the important examples of such cases are Service Tax/GST
demands on –
- Liquidated damages paid for breach of contract;
- Compensation given to previous allottees of coal blocks for cancellation of
their licenses pursuant to Supreme Court Order;
iii. Cheque dishonour fine/penalty charged by a power distribution company
from the customers;
- Penalty paid by a mining company to State Government for unaccounted
stock of river bed material;
- Bond amount recovered from an employee leaving the employment
before the agreed period;
- Late payment charges collected by any service provider for late payment
of bills;
vii. Fixed charges collected by a power generating company from State
Electricity Boards (SEBs) or by SEBs/DISCOMs from individual customer for
supply of electricity;
viii.Cancellation charges recovered by railways for cancellation of tickets,
etc.
In some of these cases, tax authorities have initiated investigation
and in some advance ruling authorities have upheld taxability.
- In Service Tax law, “Service’ was defined as any activity carried out by a
person for another for consideration. As discussed in service tax education
guide, the concept ‘activity for a consideration’ involves an element of
contractual relationship wherein the person doing an activity does so at the
desire of the person for whom the activity is done in exchange for a
consideration. An activity done without such a relationship i.e., without the
express or implied contractual reciprocity of a consideration would not be an
“activity for consideration’. The element of contractual relationship, where
one supplies goods or services at the desire or another, is an essential
element of supply.
- The description of the declared service in question, namely, agreeing to
the obligation to refrain from an act or to tolerate an act or a situation, or to
do an act in para 5 (e) of Schedule II of CGST Act is strikingly similar to the
definition of contract in the Contract Act, 1872. The Contract Act defines
‘Contract as a set of promises, forming consideration for each other.
‘Promise’ has been defined as willingness of the promisor’ to do or to abstain
from doing anything. *Consideration’ has been defined in the Contract Act
as what the promise’ does or abstains from doing for the promises made to
him.
- This goes to show that the service of agreeing to the obligation to refrain
from an act or to tolerate an act or a situation, or to do an act is nothing but
a contractual agreement. A contract to do something or to abstain from
doing something cannot be said to have taken place unless there are two
parties, one of which expressly or impliedly agrees to do or abstain from
doing something and the other agrees to pay consideration to the first party
for doing or abstaining from such an act. There must be a necessary and
sufficient nexus between the supply (i.e. agreement to do or to
abstain from doing something) and the consideration.
6.1 A perusal of the entry at serial 5(e) of Schedule II would reveal that it
comprises the aforementioned three different sets of activities viz. (a) the
obligation to refrain from an act, (b) obligation to tolerate an act or a
situation and (c) obligation to do an act. All the three activities must be
under an “agreement” or a “contract” (whether express or implied) to fall
within the ambit of the said entry. In other words, one of the parties to such
agreement/contract (the first party) must
be under a contractual obligation to either (a) refrain from an act, or (b) to
tolerate an act or a situation or (c) to do an act. Further some
“consideration” must flow in return from the other party to this
contract/agreement (the second party) to the first party for such (a)
refraining or (b) tolerating or (c) doing, Such contractual arrangement must
be an independent arrangement in its own right. Such arrangement or
agreement can take the form of an independent stand- alone contract or
may form part of another contract. Thus, a person (the first person) can be
said to be making a supply by way of refraining from doing something or
tolerating some act or situation to another person (the second person) if
the first person was under an obligation to do so and then performed
accordingly.
Agreement to do or refrain from an act should not be presumed to
exist
- There has to be an express or implied agreement; oral or written, to do
or abstain from doing something against payment of consideration for doing
or abstaining from such act, for a taxable supply to exist. An agreement to
do an act or abstain from doing an act or to tolerate an act or a situation
cannot be imagined or presumed to exist just because there is a flow of
money from one party to another. Unless there is an express or implied
promise by the recipient of money to agree to do or abstain from doing
something in return for the money paid to him, it cannot be assumed that
such payment was for doing an act or for refraining from an act or for
tolerating an act or situation. Payments such as liquidated damages for
breach of contract, penalties under the mining act for excess stock found
with the mining company, forfeiture of salary or payment of amount as per
the employment bond for leaving the employment before the minimum
agreed period, penalty for cheque dishonour etc. are not a consideration for
tolerating an act or situation. They are rather amounts recovered for not
tolerating an act or situation and to deter such acts; such amounts are for
preventing breach of contract or non-performance and are thus mere
‘events’ in a contract. Further, such amounts do not constitute payment (or
consideration) for tolerating an act, because there cannot be any contract:
(a) for breach thereof, or (b) for holding more stock than permitted under
the mining contract, or (c) for leaving the employment before the agreed
minimum period or (d) for doing something leading to the dishonour of a
cheque. As has already been stated, unless payment has been made for an
independent activity of tolerating an act under an independent arrangement
entered into for such activity of tolerating an act, , such payments will not
constitute *consideration’ and hence such activities will not constitute ”
supply” within the meaning of the Act. Taxability of these transactions is
discussed in greater detail in the following paragraphs.
Liquidated Damages
7.1 Breach or non-performance of contract by one party results in loss and
damages to the other party. Therefore, the law provides in Section 73 of the
Contract Act, 1972 that when a contract has been broken, the party which
suffers by such breach is entitled to receive from the other party
compensation for any loss or damage caused to him by such breach. The
compensation is not by way of consideration for any other independent
activity; it is just an event in the course of performance of that contract.
7.1.1 It is common for the parties entering into a contract, to specify in the
contract itself, the compensation that would be payable in the event of the
breach of the contract. Such compensation specified in a written contract for
breach of non-performance of the contract or parties of the contract is
referred to as liquidated damages. Black’s Law Dictionary defines Liquidated
Damages’ as cash compensation agreed to by a signed, written contract for
breach of contract, payable to the aggrieved party.
7.1.2 Section 74 of the Contract Act, 1972 provides that when a contract is
broken, if a sum has been named or a penalty stipulated in the contract as
the amount or penalty to be paid in case of breach, the aggrieved party shall
be entitled to receive reasonable compensation not exceeding the amount so
named or the penalty so stipulated.
7.1.3 It is argued that performance is the essence of a contract. Liquidated
damages cannot be said to be a consideration received for tolerating the
breach or non-performance of contract. They are rather payments for not
tolerating the breach of contract. Payment of liquidated damages is
stipulated in a contract to ensure performance and to deter non
performance, unsatisfactory performance or delayed performance.
Liquidated damages are a measure of loss and damage that the parties
agree would arise due to breach of contract. They do not act as a remedy
for the breach of contract. They do not restitute the aggrieved person. It is
further argued that a contract is entered into for execution and not for its
breach. The liquidated damages or penalty are not the desired outcome of
the contract. By accepting the liquidated damages, the party aggrieved by
breach of contract cannot be said to have permitted or tolerated the
deviation or non-fulfilment of the promise by the other party.
7.1.4 In this background a reasonable view that can be taken with regard to
taxability of liquidated damages is that where the amount paid as “liquidated
damages’ is an amount paid only to compensate for injury, loss or damage
suffered by the aggrieved party due to breach of the contract and there is
no agreement, express or implied, by the aggrieved party receiving the
liquidated damages, to refrain from or tolerate an act or to do anything for
the party paying the liquidated damages, in such cases liquidated damages
are mere a flow of money from the party who causes breach of the contract
to the party who suffers loss or damage due to such breach. Such payments
do not constitute consideration for a supply and are not taxable.
7.1.5 Examples of such cases are damages resulting from damage to
property, negligence, piracy, unauthorized use of trade name, copyright,
etc. Other examples that may be covered here are the penalty stipulated in
a contract for delayed construction of houses. It is a penalty paid by the
builder to the buyers to compensate them for the loss that they suffer due
to such delayed construction and not for getting anything in return from the
buyers. Similarly, forfeiture of earnest money by a seller in case of breach of
“an agreement to sell’ an immovable property by the buyer or by
Government or local authority in the event of a successful bidder failing to
act after winning the bid, for allotment of natural resources, is a mere flow
of money, as the buyer or the successful bidder does not get anything in
return for such forfeiture of earnest money. Forfeiture of Earnest money is
stipulated in such cases not as a consideration for tolerating the breach of
contract but as a compensation for the losses suffered and as a penalty for
discouraging the non-serious buyers or bidders. Such payments being
merely flow of money are not a consideration for any supply and are not
taxable. The key in such cases is to consider whether the impugned
payments constitute consideration for another independent contract
envisaging tolerating an act or situation or refraining from doing any act or
situation or simply doing an act. If the answer is yes, then it constitutes a
supply’ within the meaning of the Act, otherwise it is not a “supply”
7.1.6 If a payment constitutes a consideration for a supply, then it is taxable
irrespective of by what name it is called; it must be remembered that a
“consideration” cannot be considered de hors an agreement/contract
between two persons wherein one person does something for another and
that other pays the first in return. If the payment is merely an event in the
course of the performance of the agreement and it does not represent the
‘object’, as such, of the contract then it cannot be considered
‘consideration’. For example, a contract may provide that payment by the
recipient of goods or services shall be made before a certain date and failure
to make payment by the due date shall attract late fee or penalty. A
contract for transport of passengers may stipulate that the ticket amount
shall be partly or wholly forfeited if the passenger does not show up. A
contract for package tour may stipulate forfeiture of security deposit in the
event of cancellation of tour by the customer. Similarly, a contract for lease
of movable or immovable property may stipulate that the lessee shall not
terminate the lease before a certain period and if he does so he will have to
pay certain amount as early termination fee or penalty. Some banks
similarly charge pre- payment penalty if the borrower wishes to repay the
loan before the maturity of the loan period. Such amounts paid for
acceptance of late payment, early termination of lease or for pre-payment of
loan or the amounts forfeited on cancellation of service by the customer as
contemplated by the contract as part of commercial terms agreed to by the
parties, constitute consideration for the supply of a facility, namely, of
acceptance of late payment, early termination of a lease agreement, of pre
payment of loan and of making arrangements for the intended supply by the
tour operator respectively. Therefore, such payments, even though they
may be referred to as fine or penalty, are actually payments that amount to
consideration for supply, and are subject to GST, in cases where such supply
is taxable. Since these supplies are ancillary to the principal supply for which
the contract is signed, they shall be eligible to be assessed as the principal
supply, as discussed in detail in the later paragraphs. Naturally, such
payments will not be taxable if the principal supply is exempt.‖
- Thereafter the circular examines the taxability of the following issue:-
―Forfeiture of salary or payment of bond amount in the event of the
employee leaving the employment before the minimum agree period.‖
7.5 An employer carries out an elaborate selection process and incurs
expenditure in recruiting an employee, invests in his training and makes him
a part of the organization, privy to its processes and business secrets in the
expectation that the recruited employee would work for the organization for
a certain minimum period. Premature leaving of the employment results in
disruption of work and an undesirable situation. The provision of forfeiture of
salary or recovery of bond amount in the event of the employee leaving the
employment before the minimum agreed period are incorporated in the
employment contract to discourage non-serious candidates from taking up
employment. The said amounts are recovered by the employer not as a
consideration for tolerating the act of such premature quitting of
employment but as penalties for dissuading the non-serious employees from
taking up employment and to discourage and deter such a situation.
Further, the employee does not get anything in return from the employer
against payment of such amounts. Therefore, such amounts recovered by
the employer are not taxable as consideration for the service of agreeing to
tolerate an act or a situation.
The said circular also clarified the stand of CBIC on the issue of forfeiture of
salary or payment of bond made in the event of employee leaving the
employment before the minimum agreed period.
- Prime facie Para 5(e) of Schedule-II of CGST Act, is identically worded
as Section 66E(e) of the Finance Act, 1994. The circular expresses the stand
of CBIC in case of GST on an interpretation of an identical expression
namely:-
―agreeing to the obligation to refrain from an act, or to tolerate an act or a
situation, or to do an act.‖
The circular was not available to the adjudicating authority when the matter
was decided and he could not examine the issue in the light of the aforesaid
circular. The issue in dispute can be decided in the light of the aforesaid
circular.
- Consequently, the impugned order is set aside and the matter is
remanded to the original adjudicating authority to decide the issue afresh in
the light of the arguments given in the aforesaid circular.
(Pronounced in the open court on 10.01.2023 )
(RAMESH NAIR)
MEMBER (JUDICIAL)
(RAJU)
MEMBER (TECHNICAL)
Leave a Reply